|
Terms of Use
Digital Nation LLC, has taken every effort to design
our web site to be useful, informative, and helpful.
We ask only that you agree to, and abide by, the
following Terms and Conditions of Use. Please take a
few moments to read our Terms and Conditions of Use
carefully as, by using our site, you become
automatically subject to them. If you disagree with
any of these Terms and Conditions of Use, please do
not use this site.
Digital Nation LLC, reserves the right to make any
modifications deemed appropriate at any time. Please
continue to check these Terms and Conditions of Use
frequently to note any changes! Your continued use
of the Digital Nation LLC, web site acknowledges
that you accept any changes.
Termination of This Agreement
This agreement remains in effect until terminated by
either party. You may terminate this agreement at
any time by destroying all materials obtained from
the Digital Nation LLC web site, along with any
related documentation and all copies and
installations of software. Digital Nation LLC, may
terminate this agreement at any time and without
notice, if, in its sole judgment, any term or
condition of this agreement is breached. Upon
termination, you must destroy all materials. In
addition, we do not in any way promise that
materials supplied to our web sites will continue to
remain available after termination of our agreement.
Digital Nation LLC, is entitled to terminate all or
any part of any of its web sites without notice.
GENERAL CONDITIONS OF CONTRACT – WEB DESIGN
SERVICES
- The Contract for Web Design services is to
be based on the conditions herein or detailed in
the contractual estimate.
- A. A fifty per cent deposit is required on
all web design contracts.
B. All fees for our Search Engine and Directory
configuration and submission services are
payable in advance.
- Web Design accounts will be rendered either
monthly as the work proceeds or in stage
payments if previously agreed. Payment of all
accounts and invoices without retention or
discount is required within thirty days from the
date of invoice, interest being chargeable on
overdue accounts at 2% per month above the
Average Basic Lending Rate of the four major
clearing banks.
A. The Company will issue one statement only for
each invoice submitted.
B. Unpaid invoices will bring about automatic
suspension of any hosting solution supplied by
our hosting solutions, 30 days after invoice
date.
C. Should your hosting be suspended a
reconnection fee of 100 AED will be charged for
each reconnection of any hosting solution
requested by you to The Company in writing, such
payment to be made in advance and subject to
clearance through our bank.
D. The Company cannot be held liable for any
loss of business resulting from the termination
of any hosting accounts.
E. The Company cannot be held liable for any
potential future loss of business resulting from
the termination of any hosting accounts.
F. The Company cannot be held liable for any
loss of business resulting from the termination
of any Web Design services.- Any offer will remain open for acceptance
for a period of 60 (sixty) days from the date of
our contractual estimate. If, for any reason,
The Company is not permitted to commence the
work within 60 (sixty) days of acceptance of our
offer, we reserve the right to re-negotiate.
- Reports, drafts and all other records
provided by The Company are private and
confidential between the Client and the Company
and they may not be used or relied upon by any
other party without the prior consent of The
Company. Liability to any third party for any
reason is specifically excluded unless
separately agreed in writing.
- Title in the works together with all the
information contained therein and all data
generated under the Contract, between The
Company and the Client, shall remain vested in
The Company until the Client has discharged all
its obligations under Sections 2 to 3 inclusive
above, whereupon the benefit of the design shall
be used by the Client exclusively for the
project on which the services were originally
required, payment in accordance with Clause 2.
and 3. above does not discharge copyrights.
Liability to any third party for any reason is
specifically excluded unless separately agreed
in writing.
- Notwithstanding Condition 7 above, copyright
and all intellectual property rights in the work
prepared by The Company for the Client, shall
remain vested in The Company until such time as
all fees have been paid. The copyright and all
intellectual property rights will pass to the
Client after final payment.
- Under no circumstances shall The Company be
liable to the Client for an indirect or
consequential loss suffered by the Client
relying on the information included in the works
prepared by The Company including (without
limitation) loss of profit, loss of Contracts or
pure economic loss. Any liability is strictly
limited to the direct losses associated with
remedial costs of the work only, not to include
claims for delays, out of sequence working, non
productive overtime, award of costs, etc.
Liability to any third party for any reason is
specifically excluded unless separately agreed
in writing.
- Where the Client intends to use any work or
information provided by The Company, or any work
and information becomes involved in litigation
then the Client will both advise The Company in
writing and seek the approval prior to using the
report. The Company reserves the right to refuse
to provide documents for use in litigation.
- The total liability of The Company is to the
Client only whether as to specie, quantum or
duration of liability, no other obligations are
to be implied into the Contract, whether as to
the giving of bonds, warranties, or guarantees
unless expressly detailed therein. Liability to
any third party for any reason is specifically
excluded unless separately agreed in writing.
- The Company will use all reasonable endeavor
to meet quoted completion dates. However, time
is not the essence of the Contract and The
Company will not be liable in cases of late
reporting, however, caused, nor shall lateness
be deemed to be a breach of Contract or an act
of negligence.
- Unless specifically stated, our price does
not include for any costs or services which may
be required from other Consultants, should other
Consultants be required the client shall bear
the net costs of such.
For questions related to our Privacy Policy and
Terms of Use, please contact us for more
information.
|
